6 January 2026
Forensic Scheduling Explained: Identifying Critical Path Delays in High-Value Construction Projects
Delays are among the most common and costly causes of construction disputes. On large, high-value projects, even minor disruptions can trigger significant time overruns, increased costs, and complex contractual disagreements. Forensic scheduling plays a crucial role in understanding how and why delays occur, and in establishing responsibility when disputes arise.
By applying structured, evidence-based methodologies, forensic scheduling specialists provide clarity in situations where project timelines are contested and factual records are often incomplete or conflicting.
What Is Forensic Scheduling?
Forensic scheduling is the retrospective analysis of construction programmes to determine the causes and effects of delay. Unlike live project planning, forensic scheduling examines what actually happened on a project, using contemporaneous records to reconstruct events and assess their impact on completion dates.
The objective is to identify which activities were delayed, whether those delays affected the critical path, and which parties were responsible under the terms of the contract.
Understanding the Critical Path
The critical path represents the sequence of activities that determines the earliest possible completion date of a project. Any delay to a critical path activity will directly delay project completion unless mitigation measures are implemented.
In complex construction projects, the critical path may change over time due to design changes, sequencing adjustments, acceleration measures, or unforeseen events. Forensic scheduling experts analyse programme updates to track how the critical path evolved throughout the project lifecycle.
Common Causes of Critical Path Delays
High-value construction projects are exposed to a wide range of delay risks, including:
- Late design information or design changes
- Unforeseen ground or site conditions
- Supply chain and procurement delays
- Variations and scope changes
- Weather impacts
- Labour shortages or productivity losses
Forensic scheduling analysis examines how these events interacted with the programme and whether they genuinely affected the critical path.
Methodologies Used in Forensic Scheduling
Forensic schedulers apply recognised analytical techniques to assess delay, such as impacted as-planned analysis, time impact analysis, and as-built critical path analysis. The choice of methodology depends on the available records, contractual requirements, and the nature of the dispute.
Regardless of approach, transparency and data integrity are essential. Conclusions must be supported by contemporaneous evidence such as progress records, correspondence, site reports, and programme updates.
The Role of Forensic Scheduling in Dispute Resolution
In arbitration and litigation, forensic scheduling provides tribunals and courts with an objective explanation of how delays occurred. Expert analysis helps decision-makers understand complex project timelines and assess entitlement to extensions of time or associated costs.
Clear, well-structured scheduling evidence can significantly influence dispute outcomes and, in many cases, encourage earlier settlement by narrowing areas of disagreement.
The Value of Early Forensic Input
Engaging forensic scheduling experts early can help project stakeholders identify delay risks before disputes escalate. Early analysis supports better record-keeping, informed decision-making, and proactive mitigation strategies that reduce the likelihood of formal claims.
Conclusion
Forensic scheduling is a critical tool for identifying and explaining critical path delays in high-value construction projects. By combining technical expertise with rigorous analysis, forensic scheduling specialists bring clarity to complex timelines and support fair, evidence-based dispute resolution.
As construction projects continue to increase in scale and complexity, the importance of reliable forensic scheduling analysis in managing delay risk and resolving disputes will only continue to grow.
Come work with Us!
If you cannot carry out new cases in your current firms due to conflicts of interest, come work with us!
- Modern case management platforms
- Unrivalled team and admin support
- Clear and concise quality management systems
- Exceptional reputation
- Capacity to GROW
- Remote working
DAC is the future of working as an Expert Witness.
